Terms and Conditions of Service

Welcome to YOURAPPS | Designed By Faith. These terms and conditions outline the rules and regulations for the use of YOURAPPS' Website and engagement in our digital solution services.

By accessing this website, we assume you accept these terms and conditions. Do not continue to use YOURAPPS if you do not agree to all of the terms and conditions stated on this page.

1. Definitions

• "Company" / "We" / "Our" / "Us" refers to YOURAPPS | Designed By Faith.
• "Client" / "You" / "Your" refers to the user, customer, or business engaging our services.
• "Services" refers to the custom software, mobile, web application development, and business automation solutions provided by the Company.
• "Agreement" refers to the specific, signed contract for a defined project.

2. Project Scope and Agreement

All Services are governed by a separate, formal Service Agreement or Quotation which defines the scope, deliverables, timeline, and cost. In case of any conflict, the formal Agreement supersedes these general Terms and Conditions.

2.1. Change Requests

Changes to the original scope of work must be submitted in writing and may result in a revision of the timeline and additional charges. Work on changes will only commence upon the Client's written approval of the revised quotation.

3. Intellectual Property (IP) and Ownership

3.1. Client IP

The Client guarantees that any source materials, logos, images, or content provided to the Company for inclusion in the project do not infringe on the intellectual property rights of any third party.

3.2. Project IP (Custom Development)

Upon final payment and completion of the project as defined in the Agreement, full and complete ownership of the custom source code and unique intellectual property created specifically for the Client will be transferred to the Client. The Company retains the right to use non-unique, common libraries, frameworks, and generic utilities for other clients.

3.3. NDA Compliance

The Company strictly adheres to all non-disclosure agreements (NDAs) signed with Clients. The Company will not publish or share proprietary code, confidential data, or sensitive business logic without explicit written consent from the Client.

4. Payment Terms

Standard payment terms require a non-refundable deposit to commence work, followed by structured payments based on milestone completion, as detailed in the project Agreement. Failure to make milestone payments on time may result in the suspension of work.

5. Limitation of Liability

YOURAPPS is not liable for any direct, indirect, incidental, or consequential loss or damage arising from the use of, or inability to use, our website or the custom solutions we develop, once those solutions are in production and under the Client's management.

6. South African Law and Jurisdiction

These Terms and Conditions shall be governed by and construed in accordance with the laws of the Republic of South Africa. Any disputes relating to these terms shall be subject to the exclusive jurisdiction of the courts of South Africa (Gauteng Local Division).

Contact Us:

If you have any questions about these Terms and Conditions, please contact us at:

Email: info@yourapps.co.za